音频英文合同范本1
编号：
Contract No:
日期:
Date:
签约地点：
Signed at:
卖方：
Sellers:
地址：
Address:
邮政编码：
Postal Code:
电话：
Tel:
传真：
Fax:
买方：
Buyers:
地址：
Address:
邮政编码：
Postal Code:
电话：
Tel: 传真：
Fax:
兹确认售予买方下列货品，其成交条款如下：
The Seller hereby confirms selling the following goods on terms and conditions
(1)公差：数量及总值均有_____%的增减,由卖方决定
Tolerance: With _____% more or less both in amount and quantity allowed at the
sellers option.
(2) 原产地
Country of Origin:
(3) 付款方式：30%预付，70%发货前一周付清.
Payment terms: 30% deposit, 70% payment within one week before delivery.
(4) 交货时间：收到预付款后15天内完成装运。
Time of shipment: Within15 days after deposit received.
(5) 贸易方式：FOB Shanghai
Terms of Shipment: FOB Shanghai
(6) 包装：胶合板木盘外封铁皮
Packing： Plywood drum with steel sheet cover.
(7) 保险：由卖方按发票全额110%投保至_____为止的_____险。
Insurance： To be effected by seller for 110% of full invoice value covering _____ up to _____ only.
(8) 装运口岸：中国上海港
Port of Loading: Shanghai Port, China
(9) 转运：允许
Transshipment: Allowed
(10 分批装运：允许分批装运
Partial Shipment: Allowed
(11) 目的口岸：
Port of Destination:
(12) 唛头：Shipping Marks：
(13) 单据：Documents：
(14) 品质与数量、重量的异义与索赔：Quality/Quantity Discrepancy and Claim：
(15) 逾期发运：如果由于买方原因造成逾期发运，买方承担责任。造成自签订合同之日起超过45天不能发运的，卖方将每日按货物金额的3%收取保管费；如果由于买方原因造成逾期发运超过6个月，卖方有权自行处置定金和货物。如果是卖方原因造成的逾期发运，卖方需提前告知买方并得到买方的确认并承担其他相关费用。
LAST SHIPMENT: if the late delivery is caused by the buyer, the buyer shall bear the
responsibility. If the delay has being made more than 45 days from the signing of the Sales Contract hereof, the buyer shall pay 3% of total amount each day, and if the delay is more than 6 months, the Seller has the right to dispose the down payment and the goods. If the late delivery is caused by the Seller, the Seller shall inform the Buyer in advance and get confirmation from the Buyer, and the related expense shall be born by the Seller.
(16) 质量/数量异议：对于质量方面的异议，买方必须在货物抵达目的港后30天之类提出：对于数量方面的异议，买方必须在货物抵达目的港后15天之内提出。对由于保险公司、运输公司、其他运输机构或邮局的原因所造成的货物差异，卖方不负任何责任。 QUALITY/QUANTITY DISCREPANCY: In case of quality discrepancy, claim shall be filed by the Buyer within 30 days after the arrival of the goods at port of destination; while for quantity discrepancy, claim shall be filed by the buyer within 15 days after the arrival of the goods at port of destination. It is understood that the Seller shall not be liable, for any discrepancy of goods shipped due to causes for which the Insurance Company, Shipping Company, other transportation organization or Post Office are liable.
(17) 不可抗力：卖方对由于下列原因而导致不能或暂时不能履行全部或部分合同义务的，不负责任：水灾、火灾、地震、干旱、战争或其他任何在签约时卖方不能预料、无法控制且不能避免和克服的事件。但卖方因尽快地将所发生的事件通知对方，并应在事件发生后15天内将有关机构出具的不可抗力事件的证明寄交对方。如果不可抗力事件之影响超过120天，双方应协商合同继续履行或终止履行的事宜。
FORCE MAJEURE: Seller shall not be responsible for failure or delay in performance of entire or portion of these Sale Contract obligations in consequence of Force Majeure incidents: flood, fire, earthquake, drought, war, or any other matters couldn’t be foreseen or controlled or couldn’t be avoided. But Seller shall inform the incidents to Buyer immediately, and shall delivery the certificate of Force Majeure incidents issued by related organization within 15 days after the incidents happened. If the incidents influence more than 120 days, both parties shall negotiate to decide whether to execute or terminate the Sales Contract.
(18) 仲裁：因履行本合同所发生的一切争议，双方应友好协商解决，如协商仍不能解决争议，则应将争议提交中国国际经济贸易仲裁委员会（北京），依据其仲裁规则仲裁。仲裁裁决是终局的，对双方都有约束力。仲裁费应由败诉一方承担，但仲裁委员会另有裁定的除外。在仲裁期间，除仲裁部分之外的其他合同条款应继续执行。
ARBITRATION: All disputes across from the execution of, or in connection with this Sales Contract shall be settled friendly through negotiation, in case no settlement can be reached, the case shall then be submitted to China International Economic and
Trade Arbitration Commission, Beijing for arbitration in accordance with its provisional rules of procedure. The result of arbitration shall be born by the losing party except for the condition the Commission has other judgment. During the arbitration period, clauses beside of the arbitrated parts shall be executed.
(19) 本合同为中英文对应，一式两份，买卖双方各执一份；合同自卖方签字盖章、买方签字后生效（传真件以及扫描具有正版相等法律效应）。
The Sales Contract is concluded in Chinese and English with same effectiveness, and will come into effect on stamp of Seller and signing by Buyer. The Sales Contract is in dual original and each party shall have one original copy of this Sales Contract. (Any scanned and faxed copy shall have the same legal effect as the original one.)
(20) 备注：
Remark：
买方确认签署： 卖方确认签署：
For and on behalf of Buyer: For and on behalf of Seller:
音频英文合同范本2
party a：party b：
contract no
date：
signed at：
witnesses that the party a for considerations hereinafter named, contracts and agrees with the party b that party a will, within_____ days, next following the date hereof, build and finish a libarary building for party b. （ the building hereinafter is referred to as the said building.） the said building is of the following dimensions, with reinforced concrete, brick, stones and other materials, as are described in plans and specifications gereto annexed.
in consideration of the foregoing, party b shall, for itself and its legal representatives, promise to pay party a the sum of one million rmb yuan in manner as follows, to wit：
rmb_____at the beginning of the said work.
rmb_____on _____/ _____/_____（ for example： 3/21/XX）
rmb_____ on_____/ _____/_____
rmb_____ on_____/ _____/_____
rmb_____ on_____/ _____/_____
and the remaining sum will be paid upon the completion of the work.
it is further agreed that in order to be entitled to the said payments （ the first one excepted, which is otherwise secured ）, party a or its legal representatives shall, according to the architect''s appraisement, have expended, in labor and material, the value of the payments already received by party a, on the building, at the time of payment.
for failure to accomplish the faithful performance of the agreement aforesaid, the party so failing agrees to forfeit and pay to the other_____rmb yuan as fixed and settled damages, within one month form the time so failing.
in witness whereof we have hereunto set our hands and seals the day and year first above written.
signed, sealed and delivered
in the presence of
party a ： party b：
音频英文合同范本3
Employer: ___________ construction co., LTD. (hereinafter referred to as party a)
Contractor: _______________________________(hereinafter referred to as party b)
In accordance with the contract law of the People's Republic of China, the construction law of the People's Republic of China and the interim provisions on the administration of labor contract administration of project projects. Party a decided to ________________ company alarm project subcontracting to party b department, to standardize the management, clear responsibility, agreed by both parties, this contract is made, to abide by.
1. The contents of labor construction projects contracted by party a to party b are as follows:
All bricks, stone masonry and plastering projects in the construction blueprint of the project; Rebar production and binding sub-projects; Template making and installation of sub-projects; Scaffolding works.
Ii. Term of this contract:
From the beginning of ___________ to _______ _______ _______.
Iii. Engineering quality standard:
The quality of all itemized projects is assured.
Iv. Payment and payment method of labor management fee:
1, turned over standard: the labor service project management fee RMB $ten thousand, paid by party b, party b can achieve according to the contract that the project department and construction quality, progress of the requirements of party a according to the management fee of _____ % back to party b as a reward.
Payment method: payment of service fee shall be paid in two installments, that is, 50% before the main body is finished and 50% before the decoration is completed.
V. responsibilities of party b.
1. Party b shall provide relevant documents and qualifications and cooperate with party b to handle relevant procedures.
To coordinate labor disputes and industrial accidents during construction.
Vi. Responsibilities of party b:
1, I am grateful to fully perform __________________ company and construction co., LTD. The project construction contract signed. And shall bear all the responsibilities and obligations of party b in the contract.
2. Ensure the quality, progress and safety of all sub-projects to meet the contract requirements signed by the project department and the construction party. If not, it will be punished by 50% of the management fee.
Vii. Matters not covered herein shall be negotiated by both parties, and the supplementary provisions may be signed by the parties hereto, which shall have the same legal effect as this contract.
Viii. This contract is made in six originals, with each party holding three copies. The contract shall be executed by both parties and shall be completed upon completion of the project.
Party a: _______________________ party b: ________________________
Party a's representative: __________________ party b's representative: __________________.
中文版
发包方：___________建筑施工有限责任公司(以下简称甲方)
承包方：_______________________________(以下简称乙方)
依照《_合同法》、《_建筑法》及公司《关于工程项目劳务承包管理暂行规定》。甲方决定将________________公司______________工程项目部的劳务分包给乙方，为规范管理，明确职责，经双方协商一致，特签订本合同，以资共同遵守。
一、甲方发包给乙方的劳务施工项目内容范围如下：
该工程项目施工蓝图中所有砖、石砌筑及抹灰分项工程;钢筋制作、绑扎分项工程;模板制作、安装分项工程;脚手架搭设作业。
二、本合同期限：
从______年_____月起至___________年_______月止。
三、工程质量标准：
所有分项工程质量确保优良
四、劳务管理费的上缴及付款方式：
1、上缴标准：该工程项目劳务管理费为人民币壹拾万元整，由乙方上缴，如乙方能达到按该项目部与建设方所签订的合同中的质量、进度要求，则甲方按管理费的____ %返回乙方作为奖励。
付款方式：上缴劳务管理费按两次付清，即主体完工前付50%，装修完工前付50%。
五、乙方的职责
1、乙方提供相关的.证件及资质，配合乙方办理相关手续。
协调处理施工过程中的劳务纠纷及工伤事故。
六、乙方的职责：
1、全面履行__________________公司与_________________-建筑施工有限责任公司签订的项目施工合同。并承担该合同条款中乙方应承担的全部责任与义务。
2、确保所有分项工程的质量、进度、安全达到项目部与建设方签订的合同要求。如达不到则按管理费的50%进行处罚。
七、本合同未尽事宜，双方通过协商，可另签订补充条款，与本合同具有同等法律效力。
八、本合同一式六份，甲乙双方各执三份，经双方签字生效，至工程完工，双方结清劳务管理费后失效。
甲方：_______________________乙方：________________________
甲方代表：__________________ 乙方代表：__________________
音频英文合同范本4
RETAINING CONTRACT
法律顾问合同
By and between
签约方
Client
当事人
And
Chongqing Guangxian Law Offices
重庆广贤律师事务所
November, 20xx二O一三年十一月
1. The Parties 缔约方 ........................................................................ 3
2. Backgrounds缔约基础 .................................................................. 3
3. Services Rendered服务内容与责任 ............................................. 4
4. Litigation or Arbitration Service诉讼和仲裁服务 ....................... 5
5. Obligations of Client当事人的义务 ............................................. 6
6. Fee and Payment顾问费用与支付 ............................................... 6
7. Work Implementation 工作方式 .................................................. 7
8. Remedies 违约责任 ...................................................................... 7
9. Supplementary Agreements 补充协议 ......................................... 8
10. Miscellaneous一般约定 .............................................................. 8
RETAINING CONTRACT
法律顾问合同
Contract Number: 合同号
1. The Parties 缔约方 People’s Republic of China as of is entered into by and between:本服务合同（以下简称合同）于20xx年11月6日在_重庆市由以下双方订立：
. (“Client”) 重庆当事人（以下简称当事人）
And 和
. Chongqing GuangXian Law Offices (“Guangxian”), a recorded law firm underlaws of People’s Republic of China of which address is 162 3rd Zhongshan Lu, Eich Int'l Plaza 16/F, Yuzhong District, Chongqing, 400015, People's
Republic of China重庆广贤律师事务所（以下简称广贤），系根据_法律成立的注册律师事务所，地址位于重庆市渝中区中山三路162号中安国际大厦16层，邮编：400015
. Client and Guangxian shall hereinafter be referred to individually as the "Party"and collectively as the"Parties". 当事人和广贤可单独称为“一方”，合称为“双方”。
2. Backgrounds缔约基础
. In accordance with the Lawyers Act and Contract Act of the People’s Republic
of China, Client engages Guangxian as its retained Attorneys to deal with legal affairs in its business operation.根据《_律师法》和《_合同法》，当事人聘请广贤处理法律事项。
. Guangxian agrees to accept such engagement as stipulated in the last paragraph.
广贤同意接受前述聘请。
INWITNESS THEREFORE, The Parties hereby agree as follows: 为此，双方特此订立如下条款：
3. Services Rendered by Guangxian to Client 广贤的服务内容与责任
. Important Contract Review or Draft重大合同审查或起草
According to Client’s request Guangxian shall legally review or draft contract
documents for any kind of routine business including but not limited to the guarantee contract, loan contract, construction contract, technology contract, intellectual
property transfer or license contract, materials procurement contract, product sales agreement, service contract, labor contract etc. for Client without specialized project contract;应当事人要求，对当事人拟签订各类重要合同，包括但不限于担保合同、贷款合同、建设工程合同、技术合同、知识产权转让、许可使用合同、物资的采购协议、产品经销协议、产品服务协议、劳动合同、劳务合同，进行法律审查或起草合同文本，但属于专项法律服务内容的除外；
. Internal Rules and Regulations Review 制度审查
According to Client’s request Guangxian shall review any important internal rules and regulations relevant to its employees, sales contributor, supplier or based on any legal or regulatory rules including environmental protection, fire fighting, accounting or financial issues;应当事人要求，就当事人内容涉及当事人与其员工、经销商、供应商或根据法律法规或监管规则（例如：环境法规、消防法规、会计法或会计规则、财政税法等）要求建立的，重要规章制度进行法律审查。
. Attorney’s Opinions 法律意见
According to Client’s request, Guangxian shall submit opinions for any issue revolved in Client’s business and internal management. 应当事人要求，就当事人业务活动和内部经营管理中涉及的法律问题提供法律意见。
. Attorney’s Letter发出律师函
According to Client’s request, to resolve all relevant disputes of both internal and outside business with Attorney’s Letter to Client’s debtor or relevant party.
应当事人要求，就当事人在业务活动及内部经营管理活动中出现的各类纠纷提供咨询意见或建议，发出律师函。
. Legal Training法律知识培训
In accordance with Client’s request, Guangxian shall provide legal training for
Client’s relevant employees.应当事人要求，对当事人的相关人员进行法律知识和运用技巧的培训或举办法律讲座。
. Documents Legal Review文件的法律审查
In accordance with Client’s request, review or draft any documents with legal binding force or take any obligation, including but not limit to post, publicity, representation, advertisement words, external promise or bids;
应当事人要求，就当事人对外发布的具有法律约束力或以承担一定义务为内容的文件，包括但不限于公告、公示、声明、广告语、对外承诺、招标文件等，进行法律审查或拟定相关文本。
. Deals Introduction
In accordance with the request of Client, recruit and introduce any partner or investment for Client, supply any operational project or relevant information;
根据当事人的要求，招募并引荐合营或合作伙伴或投资者(以下简称引荐客户)，招募并引荐经营项目或提供相关信息；
. Monthly Report
Provide legal information pertained to the business of Client. Such kind of report shall be delivered monthly.
为当事人经营活动按月提供法律信息。此类报告应当按月提供。
4. Litigation or Arbitration Service诉讼和仲裁服务
. Guangxian’s service shall exclude litigation or arbitration. Client may consult
Guangxian for general analysis of any litigation before brings lawsuit or within three days after receiving a court summons. Guangxian shall supply legal
consulting service based hereunder.
广贤律师提供的其它法律事务服务不包括诉讼仲裁业务，当事人诉讼业务
音频英文合同范本5
技 术 合 作 协 议
Technical Cooperation Agreement
甲方：XX油脂化学有限公司
Party A: XX Grease Chemical Co. , Ltd.
地址： XX高新技术工业园
Address:XXHigh-tech Industrial Park
法定代表人：XXX
Legal Representative: XXX
乙方：
Party B:
地址：
Address:
本协议合作双方就组建技术研发团队事项，经过平等协商，在真实、充分地表达各自意愿互惠互利的基础上，根据《_合同法》的规定，达成如下协议，并由合作各方共同恪守。
This Agreement, concerning the setting up of a technical research and development team, is made according to the Contract Law of PRC regulations and entered into through equal negotiation by both Parties as the free and full expression of their own wishes to mutual benefits, and to this end both Parties shall abide by this Agreement as following.
第一条、 甲方同意雇用乙方为新产品研发技术顾问。乙方同意为甲方提供技术
顾问服务。
Article 1: Party A hereby agrees to employ party B as the technical consultant for the new product research and development. Party B hereby agrees to offer technical consultation service to Part A.
第二条、 甲方同意每月支付乙方的研究费用，包括：薪资、办公费、检测费、
差旅费以及其他相关费用。
Article 2: Party A hereby agrees to pay Party B for the research each month, including salaries, administrative expenses, detection cost, traveling expenses and other cost associated.
第三条、 乙方有责任为甲方提供相关国内外技术及市场信息，并及时答复甲方
技术上所遇到的问题。
Article 3：Party B is responsible to provide relevant technical and market information home and abroad and is ready to answer any technical problem frequently asked by Party A.
第四条、 乙方有义务向甲方提供有关个人简历和相关证明材料，甲方要尊重乙
方个人隐私，有义务妥善保管相关材料。
Article 4: Party B shall has the obligation to provide Party A with any relevant personal resume and reference documents as necessary. Party A shall respect the personal privacy of Party B and has the obligation to properly keep those materials.
第五条、 乙方同意所研发的产品所有知识产权归甲方所有，乙方不得将相关技
术信息泄露给任何第三方，否则需要承担一切法律后果。
Article 5: Party B hereby agrees that the intellectual property of any product as researched and developed herein shall be owned by Party A. Party B shall not be allowed to disclose any technical information concerned to the third party, or it shall take all the legal consequences.
第六条、 甲乙双方同意通过紧密合作达到共同目标；每年增加一到三个项目；
每年申请一到三个发明专利；每年完成一到两个能够通过专家认证的
新产品；每年至少向市场推广两个产品。
Article 6: Both Parties agree to achieve their common goals by their close cooperation. It is planned to add one to three projects each year and to apply for one to three patents for inventions each year, to make one to two new products certified by experts each year, and to promote at least two products to the market each year.
第七条、 此协议甲乙双方各执一份，没有在协议中提到的事项双方需协商解决。 Article 7: This Agreement is held by both Parties, one for each respectively. Any issue not mentioned in this Agreement shall be settled by both Parties through negotiation.
此协议从签字当日起生效。
This Agreement shall take effect from the date of signature.
甲方：乙方：
Party AParty B:
签字：签字：
Signature: Signature:
日期：日期：
DateDate:
音频英文合同范本6
编号： no：
日期： date ：
签约地点： signed at：
卖方：sellers：
地址：address： 邮政编码：postal code：
电话：tel： 传真：fax：
买方：buyers：
地址：address： 邮政编码：postal code：
电话：tel： 传真：fax：
买卖双方同意按下列条款由卖方出售，买方购进下列货物：
the sellers agrees to sell and the buyer agrees to buy the undermentioned goods on the terms and conditions stated below:
1 货号 article no.
2 品名及规格 description&specification
3 数量 quantity
4 单价 unit price
5 总值：
数量及总值均有_____%的增减,由卖方决定。
total amount
with _____% more or less both in amount and quantity allowed at the sellers option.
6 生产国和制造厂家 country of origin and manufacturer
7 包装： packing：
8 唛头： shipping marks：
9 装运期限：time of shipment：
10 装运口岸：port of loading：
11 目的口岸：port of destination：
12 保险：由卖方按发票全额110%投保至_____为止的_____险。
insurance：to be effected by buyers for 110% of full invoice value covering _____ up to _____ only.
13 付款条件：
买方须于_____年_____月_____日将保兑的，不可撤销的，可转让可分割的即期信用证开到卖方。 信用证议付有效期延至上列装运期后15天在中国到期，该信用证中必须注明允许分运及转运。
payment：
by confirmed, irrevocable, transferable and divisible l/c to be available by sight draft to reach the sellers before ___/___/_____ and to remainvalid for ingotiation in china until 15 days after the aforesaid time of shipment. tje l/c must specify that transhipment and partial shipments are allowed.
14 单据：documents：
15 装运条件：terms of shipment：
16 品质与数量、重量的异义与索赔：quality/quantity discrepancy and claim：
17 人力不可抗拒因素：
由于水灾、火灾、地震、干旱、战争或协议一方无法预见、控制、避免和克服的其他事件导致不能或暂时不能全部或部分履行本协议，该方不负责任。但是，受不可抗力事件影响的一方须尽快将发生的事件通知另一方，并在不可抗力事件发生15天内将有关机构出具的'不可抗力事件的证明寄交对方。
force majeure：
either party shall not be held responsible for failure or delay to perform all or any part of this agreement due to flood, fire, earthquake, draught, war or any other events which could not be predicted, controlled, avoided or overcome by the relative party. however, the party affected by the event of force majeure shall inform the other party of its occurrence in writing as soon as possible and thereafter send a certificate of the event issued by the relevant authorities to the other party within 15 days after its occurrence.
18 仲裁：
在履行协议过程中，如产生争议，双方应友好协商解决。若通过友好协商未能达成协议，则提交中国国际贸易促进委员会对外贸易仲裁委员会，根据该会仲裁程序暂行规定进行仲裁。该委员会决定是终局的，对双方均有约束力。仲裁费用，除另有规定外，由败诉一方负担。 arbitration
all disputes arising from the execution of this agreement shall be settled through friendly consultations. in case no settlement can be reached, the case in dispute shall then be submitted to the foreign trad arbitration commission of the china council for the promotion of international trade for arbitration in accordance with its provisional rules of procedure. the decesion made by this commission shall be regarded as final and binding upon both parties. arbitration fees shall be borne by the losing party, unless otherwise awarded.
音频英文合同范本7
Unit: (hereinafter referred to as Party A)
Advertisers: (hereinafter referred to as Party B)
After friendly consultation between Party A and B, in accordance with the principle of mutual benefit and mutual benefit, the following articles are reached on Party A's propaganda and planning on Party B's entrustment:
Article 1: Party A entrusts Party B to publicity planning project: _________________________
___________________________________________________________
The second article: the principle of propaganda and planning
Party B provides the whole process of publicity and planning, including advertising planning and design services, providing reference for Party A's market positioning and market area and serving for decision-making.
The third one: the way of agency
Party a commissioned party B to complete the whole process of propaganda and planning, and entrusted the plane design, advertising agency and other business, fully responsible for the project publicity and planning.
Fourth: the rights and obligations of Party A
1. In the agreed period, Party B should be required to submit the relevant propaganda and planning scheme, and the Party A will assist the organization after the confirmation of the market investigation.
2, it has the right to require Party B to provide written opinions and suggestions from the angle of planning within the scope of the Commission.
3, Party B will be required to provide Party A with planning plans and adjustment of propaganda strategies and suggestions.
4, to approve the overall propaganda strategy formulated by Party B, and to bear all the costs related to publicity and promotion, advertising and so on.
5, payment shall be paid in accordance with the agreement of the contract with Party B for the payment of the publicity and planning fee and on time.
The fifth, the rights and obligations of Party B
1, the party shall have the right to pay the publicity and planning fee in accordance with the requirements of the contract.
2, in accordance with the requirements of Party A and the different stages of the project progress, put forward the advertising plan, after the approval of Party A to organize the implementation.
3, Party B provides:
The newspaper project soft article writing; the project, all kinds of exhibitions, promotions, activities planning.
4, bear the claim or other legal liability caused by Party B's fault.
Sixth: the term of agency
Party A entrusts Party B publicity planning period is divided into: ______ years ___ month ___ to ______ ___ ___ date month year;
Seventh: standard and mode of payment for project publicity and planning
1, publicity planning fees totaling $________ yuan (capital ______________________).
2, after the signing of this contract, Party A will pay to Party B RMB ____________ whole (capital ___________________________) for payment.
3, after the end of the contract, Party A shall pay the balance, namely RMB ____________________ whole (capital ________________________).
The eighth article: liability for breach of contract
1. Party A is responsible for all the losses caused by Party A's failure to provide relevant license and relevant legal documents and preferential policies for activities.
2. If the Party B does not provide the plan of publicity and planning in time because of Party B's reasons, Party A shall investigate the responsibility or terminate the contract.
3. Party A shall have the right to rescind the contract if Party A fails to pay Party B publicity and planning fees according to the agreement.
4. In the course of cooperation, the other party has the right to require the other party to bear the related economic loss by disclosing the business secrets or providing the relevant information to the third party.
5, any party to terminate the contract without authorization to suspend unilateral breach of contract or shall be borne by the defaulting party, must therefore have caused losses to the observant party and liability for breach of contract.
6, in the execution of this contract, if there is a force majeure factor affecting the execution of the relevant provisions, it shall be settled by the two sides and properly resolved. It is not a breach of contract to terminate the contract or change the relevant provisions of the contract on the basis of the agreement between the two parties.
Ninth: Annex
1, both parties may supplement the terms of this contract and sign a supplementary agreement in written form. The supplementary agreement has the same legal effect as this contract.
2. The annexes of this contract are all valid parts of the contract and have the same effect.
3. All matters not specified in this contract and its annexes and supplementary agreements are carried out in accordance with the relevant laws, regulations and regulations of the People's Republic of China.
4. The contract is two copies, each party and Party B has one copy, all with the same legal effect.
5. In the event of a dispute in the performance of this contract, the parties shall settle the dispute by negotiation, negotiation or adjustment, and the parties agree to be arbitrated by the Arbitration Commission.
6. The contract will terminate naturally after the expiration of the contract. If the two parties renew the contract, they shall make a written opinion to the other party seven days before the expiration of the contract.
7. This contract shall come into force on the date of signature or seal of the representatives of the two parties.
Party A: Party B:
Representative: (signature) representative: (signature)
Date: day and date: day and day
中文版
单 位：（下简称甲方）
广告商：（下简称乙方）
甲、乙双方经友好协商，本着互惠互利的原则，就甲方委托乙方的宣传策划事宜，达成如下条款：
第一条：甲方委托乙方宣传策划的项目：_________________________
___________________________________________________________
第二条：宣传策划原则
乙方按甲方规定，提供全程宣传策划包括广告策划与设计的服务，为甲方市场定位及市场区域提供参改依据，为决策服务。
第三条：代理方式
甲方委托乙方全权全程宣传策划，并委托平面设计、广告代理等业务，全面负责本次项目的宣传策划工作。
第四条：甲方的权利和义务
1、在约定期限内要求乙方提交有关宣传策划方案，从市场调查依据确认后再由甲方协助组织实施。
2、有权要求乙方在委托范围内从策划角度提供书面意见和建议。
3、要求乙方向甲方提供策划方案及调整宣传策略和建议。
4、批准乙方制订的整体宣传策略，承担有关宣传推广、广告等所需的各项费用。
5、按合同约定与乙方结算宣传策划费并按时支付。
第五条、乙方的权利和义务
1、有权按照合同要求甲方支付宣传策划费。
2、负责根据甲方要求和项目进度的不同阶段，提报广告计划，经甲方认可后组织实施。
3、乙方提供：
⑴、项目报纸软性文章撰写；⑵、项目各种展销、促销、优惠活动的策划。
4、承担因乙方过错造成的索赔或其他法律责任。
第六条：代理期限
甲方委托乙方宣传策划期限分为： ______年___月___日至______年___月___日止；
第七条：项目宣传策划费的给付标准和方式
1、宣传策划费共计￥________元（大写______________________）。
2、本合同签订后，甲方即向乙方支付人民币￥____________整（大写___________________________）为预付款。
3、活动结束后，甲方向乙方支付合同余款，即人民币￥____________________整（大写________________________）.
第八条：违约责任
1、因甲方未提供有关许可证及相关法律文件资料、活动优惠政策而造成损失的，则甲方承担全部责任。
2、如因乙方原因，不及时提供宣传策划方案，甲方追究责任或终止合同。
3、甲方如未按照双方约定支付给乙方宣传策划费，乙方有权解除合同。
4、在合作过程中任何一方泄露商业秘密或将有关资料提供给第三人的，另一方有权要求对方承担相关经济损失。
5、任何一方单方擅自中止合同或解除合同均属违约行为，需由违约方承担因此给守约方造成的相关损失和违约责任。
6、本合同执行过程中，如有因不可抗力因素影响有关条款之执行的，应由双方协商，妥善解决，在双方达成一致意见的基础上而中止合同或改变合同的有关条款的不视为违约。
第九条：附则
1、双方可对本合同的条款进行补充，以书面形式签订补充协议。补充协议与本合同具有同等法律效力。
2、本合同之附件均为合同有效组成部分，具有同等效力。
3、本合同及其附件和补充协议中未规定的事宜，均遵照_有关法律、法规和规章执行。
4、本合同壹式贰份，甲乙双方各执壹份，均具同等法律效力。
5、本合同在履行中如发生争议，双方应协商解决，协商或调节不成的，双方同意由仲裁委员会仲裁。
6、合同期满本合同自然终止。双方如续订合同，应在该合同期满七天前向对方提出书面意见。
7、本合同自双方代表人签字或盖章之日起生效。
甲 方：乙 方：
代表人：(签章)代表人：(签章)
日期：年 月日 日期： 年 月 日
音频英文合同范本8
GARMENTS PURCHASE CONTRACT
Contract NO.合同编号：
Date签约日期：
Buyer: 买方：
Seller: 卖方：
This purchase contract (hereafter abbreviated “contract”) is signed by and between the Buyer and the Seller upon equal negotiations based on the Contract Law and other relevant laws and regulations. Both parties agree to sell and buy goods on following terms and conditions.
此销售合同（以下简称“合同”）根据合同法及相关法律法规并经由买卖双方经平等协商后共同签定，买方与卖方均同意以下条款和条件购买和出售货物。
Purchasing Contract terms and conditions of garments Season: 服装采购合同条款：
1. Description, quantity, unit price, total amount and other details of the goods ordered please refer to detail order, invoice and packing list. The name of the issuing company of invoice must be the same as the seller.
采购品名、规格、数量、单价、总价、交期等参考每次采购相应订单、发票及装运单，发票的填开单位必须与本合同中卖方的名称相一致。
2. Country of origin: China原产地：中国
3. Delivery: The seller shall deliver the goods to the warehouse as previously agreed between the two parties.
交货方式：卖方应把货物送交至双方事先约定的仓库。
4. The quality of all the garments shall answer for the updated, valid Standard of the Nation and the industry. In case the garments are unqualified or for other reason that shall ascribe the seller’s fault, which brings losses of or damages (including but
not limited to fine, expropriate, damage to Goodwill, lawyer’s fee and other losses for the buyer ’s breach of law or contract because of the seller fault) to the buyer, the buyer shall has the right to ask seller for damages.
所有服装质量应符合最新、有效的国家标准、行业标准的规定，若卖方交付的服装质量不合格或其他任何可归咎于卖方的责任导致买方遭受的任何损失（包括但不限于罚没款、扣款、商誉损失、律师费及其他因卖方原因导致买方违约、违法所遭受的损失），买方有权要求卖方承担。
5. Seller shall provide 7 original copies of "Approved" Quality Inspection Certificate for each fabric used to produce MOTIVI different models 7 days before the delivery date. The certificate must be issued by a Chinese official quality testing department, the samples that the seller send to quality test lab shall be representative, can represent the quality of the goods, and the test must follow the Basic Standard GB18401 and include the composition of the fabric. The buyer will settle the payment according to the contract after received the test report and other related documentations (Packing list, Invoice of Goods etc.).
卖方应于交货日七日前向买方提供由中国官方质检部门认可的质检机构出具的所有用来制作服装的面料的合格质检报告原件7 份，卖方向质检机构送检的样品应具有代表性，能够代表大货质量，质检报告应包含纤维含量及国家标准 GB18401 的安全技术要求事项。买方在收到质检报告、装箱单、货物发票等其他文件后按合同约定付款。
6. For all the goods, the seller shall issue invoice to the buyer, the invoice shall be invoiced 所有货物应由卖方向买方开具发票，发票抬头需开列买方单位名称为
Kind of invoice issued: People’s Republic of China VAT invoice
发票开立种类：_增值税专用发票。
7. Terms of Payment: Total amount of payment of goods shall be paid in RMB within 30 days issued the invoices.
付款： 开立发票后30日内以人民币支付。
Upon signing the contract, the seller shall provide bank information for the buyer to effect payment.
买卖双方签定订购合同后，卖方需提供公司银行资料给予买方支付货款.。
8
